Terms and Conditions for mRova Solutions:
Scope of work
a. mRova Solutions agrees to provide website development services to the client as outlined in the project proposal. The proposal includes project details, estimated timeline, and pricing.
b. The client is responsible for providing all necessary information, materials, and approvals required for the project.
c. mRova Solutions reserves the right to refuse any project that is deemed inappropriate or illegal.
Intellectual property rights
a. All materials created by mRova Solutions for the client’s website, including but not limited to designs, source code, and content, are the property of mRova Solutions until final payment is received.
b. The client agrees to grant mRova Solutions the right to use any materials provided by the client for the project, including but not limited to logos, images, and text, solely for the purpose of completing the project.
c. Upon final payment, ownership of all materials created by mRova Solutions for the client’s website will transfer to the client.
a. mRova Solutions requires a deposit of [XX]% of the project cost before work can begin.
b. Payment milestones will be outlined in the project proposal.
c. Final payment is due upon completion of the project and prior to website launch.
d. Late payment or non-payment may result in a delay or suspension of work and may be subject to additional fees or legal action.
a. All information provided by the client to mRova Solutions, including but not limited to business plans, financial data, and customer information, will be considered confidential and will not be disclosed to third parties without the client’s consent.
b. mRova Solutions will take reasonable measures to protect the client’s confidential information but will not be liable for any damages resulting from a breach of confidentiality caused by a third party.
a. mRova Solutions will not be liable for any damages, including but not limited to lost profits, business interruption, or data loss, arising from the use or inability to use the website or its content.
b. The client agrees to indemnify and hold mRova Solutions harmless from any claims or damages resulting from the client’s use of the website.
a. Either party may terminate the project at any time by providing written notice.
b. The client is responsible for paying for all services provided by mRova Solutions up until the termination date.
c. If the project is terminated by mRova Solutions due to the client’s breach of contract, mRova Solutions may retain any deposits or payments made by the client.
a. Any disputes arising from this agreement will be resolved through arbitration in accordance with the rules of the American Arbitration Association.
b. The decision of the arbitrator will be binding and final.
a. This agreement will be governed by and construed in accordance with the laws of the State of Maharashtra.
By signing this agreement, the client acknowledges that they have read and agree to the terms and conditions outlined above.